1. Skip to navigation
  2. Skip to content
  3. Skip to sidebar

Emergency Paid Sick Leave for COVID-19: What Government Contractors Need to Know

To date, Congress has enacted three pieces of legislation, described as “phases 1 through 3,” to respond to the COVID-19 epidemic. This legislation has both expanded requirements for sick leave and provided additional funding for contractors who have incurred costs retaining employees that are unable to work due to the closure of a federal site. Relevant provisions of the legislation, and the class deviation issued by the Department of Defense (“DoD”) for implementation of the CARES Act requirements in the DoD Federal Acquisition Regulation Supplement (“DFARS”) which we previously addressed in this blog on April 9, are discussed here.

Members of the Dentons’ Government Contracts Practice Group are available to assist government contractors regarding their obligations for paid sick leave under new or existing Federal legislation.

, , , ,

Emergency Paid Sick Leave for COVID-19: What Government Contractors Need to Know

Government Contracts Legislative and Regulatory Update – April

Regulation update

The April edition of Dentons’ monthly legislative and regulatory update is available!

, ,

Government Contracts Legislative and Regulatory Update – April

DOD Implementation of CARES Act Section 3610

On April 8, 2020, the Department of Defense issued a class deviation implementing CARES Act Section 3610, Federal Contractor Authority. Specifically, the Class Deviation, which is effectively immediately, authorizes contractors to use a new Department of Defense Federal Acquisition Regulation Supplement (DFARS) Part 231 clause—DFARS 231.205-79, CARES Act Section 3610 Implementation—”as a framework for implementation of section 3610″ of the CARES Act. The Class Deviation identifies that Section 3610 can provide “reimbursement on any contract type.”

Most notably in DFARS 231.205-79, provided below, is that:

  • It only applies to contractors for which the “cognizant contracting officer has established in writing to be an affected contractor.”  This is an important distinction and contractors should ensure to obtain, and maintain in its contract files, this affirmation from the contracting officer; 
  • It clarifies both that it applies to “work on a site that has been approved for work by the Federal Government, including on a government-owned, government-leased, contractor-owned, or contractor-leased facility approved by the federal government for contract performance,” which provided needed clarity to the language in the CARES Act, and that the performance location can be deemed inaccessible because of local shelter in place orders; and
  • In order for costs to be allowable, they must be “segregated and identifiable in the contractor’s records so that compliance with all terms of this section can be reasonably ascertained.”

DFARS 231.205-79 CARES Act Section 3610 – Implementation

  1. Applicability.
    1. This cost principle applies only to a contractor:
      1. that the cognizant contracting officer has established in writing to be an affected contractor;
      2. whose employees or subcontractor employees:
        1. Cannot perform work on a government-owned, government-leased, contractor-owned, or contractor-leased facility or site approved by the federal government for contract performance due to closures or other restrictions, and
        2. Are unable to telework because their job duties cannot be performed remotely during the public health emergency declared on January 31, 2020, for Coronavirus (COVID–19).
    2. The maximum reimbursement authorized by section 3610 shall be reduced by the amount of credit a contractor is allowed pursuant to division G of the Families First Coronavirus Response Act (Pub. L. 116– 127) and any applicable credits a contractor is allowed under the CARES Act (Pub. L. 116-136) or other credit allowed by law that is specifically identifiable with the public health emergency declared on January 31, 2020 for COVID–19.
  2. Allowability.
    1. Notwithstanding any contrary provisions of FAR subparts 31.2, 31.3, 31.6, 31.7 and DFARS 231.2, 231.3, 231.6, and 231.7, costs of paid leave (including sick leave), are allowable at the appropriate rates under the contract for up to an average of 40 hours per week, and may be charged as direct charges, if appropriate, if incurred for the purpose of:
      1. Keeping contractor employees and subcontractor employees in a ready state, including to protect the life and safety of Government and contractor personnel, notwithstanding the risks of the public health emergency declared on January 31, 2020, for COVID-19, or
      2. Protecting the life and safety of Government and contractor personnel against risks arising from the COVID-19 public health emergency.
    2. Costs covered by this section are limited to those that are incurred as a consequence of granting paid leave as a result of the COVID-19 national emergency and that would not be incurred in the normal course of the contractor’s business. Costs of paid leave that would be incurred without regard to the existence of the COVID-19 national emergency remain subject to all other applicable provisions of FAR subparts 31.2, 31.3, 31.6, 31.7 and DFARS 231.2, 231.3, 231.6, and 231.7. In order to be allowable under this section, costs must be segregated and identifiable in the contractor’s records so that compliance with all terms of this section can be reasonably ascertained. Segregation and identification of costs can be performed by any reasonable method as long as the results provide a sufficient audit trail.
    3. Covered paid leave is limited to leave taken by employees who otherwise would be performing work on a site that has been approved for work by the Federal Government, including on a government-owned, government-leased, contractor-owned, or contractor-leased facility approved by the federal government for contract performance; but
      1. The work cannot be performed because such facilities have been closed or made practically inaccessible or inoperable, or other restrictions prevent performance of work at the facility or site as a result of the COVID-19 national emergency; and
      2. Paid leave is granted because the employee is unable to telework because their job duties cannot be performed remotely during public health emergency declared on January 31, 2020, for COVID-19.
    4. The facility at which work would otherwise be performed is deemed inaccessible for purposes of paragraph (b)(3) of this subpart to the extent that travel to the facility is prohibited or made impracticable by applicable Federal, State, or local law, including temporary orders having the effect of law.
    5. The paid leave made allowable by this section must be taken during the period of the public health emergency declared on January 31, 2020, for COVID–19, up to and including September 30, 2020.
    6. Costs made allowable by this section are reduced by the amount the contractor is eligible to receive under any other Federal payment, allowance, or tax or other credit allowed by law that is specifically identifiable with the public health emergency declared on January 31, 2020, for COVID–19, such as the tax credit allowed by division G of Public Law 116–127.

The Class Deviation can be found here and remains in effect until rescinded.

, , , ,

DOD Implementation of CARES Act Section 3610

Government Contracting During the COVID-19: Key Considerations for Negotiating New Government Contracts Amidst the Global Pandemic

Regulation update

The COVID-19 global pandemic and the United States’ response to the national emergency are having significant impacts on the government contractor community, shaping the way contractors perform their current contractual obligations and the way contractors will negotiate future contracts, task orders, and modifications. Indeed, for contractors preparing proposals or negotiating new contracts, the landscape is now much different and more uncertain than it was prior to the COVID-19 global pandemic.

To assist contractors in protecting against these uncertainties, we have outlined below considerations and strategies that should be employed (additional details related to each of the below identified strategies may be found here):

  • Understand the contract or subcontract type being negotiated and, in particular, the risk tradeoffs of flexibly priced contracts versus fixed price contracts – Fixed price contracts and subcontracts are designed to place the maximum risk on the seller for reasonably foreseeable risks; because the pandemic is a known fact, those considering a fixed price contract must proceed with caution.
  • Understand that the government may assert the basic FAR excusable delay clause has limited applicability to new government contracts because COVID-19 is now a known fact – The government may argue that when a potential risk exists at the time of award, any impact to the contract stemming from that risk may be foreseeable and inexcusable under the FAR delay clauses. In order to protect against this risk, contractors should consider including disclaiming language in their proposals and, to the extent possible, negotiate a reopener or other special clause that makes clear that the full impact of COVID-19 is not foreseeable and the contractor does not assume such risks to schedule or cost.
  • Consider how the contingencies cost principle affects contractors’ ability to include the costs of unforeseeable events in their proposals – Because COVID-19 is a presently known condition with an impact that likely cannot be measured with accuracy at this time, the government may take the position that any contingency, management reserve, or other cost associated with potential impacts arising from COVID-19 are unallowable and must be excluded from cost estimates. To protect against this risk, contractors should seek higher fee and/or the inclusion of reopener clauses in their contracts that permit the parties to reopen cost or price negotiations based on future COVID-19 related events.
  • Monitor indirect cost rates carefully and make adjustments to forward pricing rates and billing rates as necessary. Terminate existing Forward Pricing Rate Agreements – In order to protect against the risk of a quick change to indirect rates, contractors should carefully monitor how COVID-19 related issues are impacting rates and take appropriate action, including, but not limited to, terminating FPRAs and updating forward pricing rates and billing rates.
  • Prepare for a potential increase in sole source contracts and/or limited bid protests – If the government does utilize a full and open procurement competition, be aware that the government may override the automatic stay of performance in GAO bid protests, pursuant to FAR § 33.104(c)(2)).

Contractors should expect extraordinary circumstances as a result of the global pandemic, including rapid procurement processes for new government contracts, variable (and likely increased) contract performance costs, and disrupted contract performance schedules. Vigilant and proactive contractors may be able to create contractual protections, especially when entering into new government contracts, that may minimize financial repercussions of COVID-19.

, ,

Government Contracting During the COVID-19: Key Considerations for Negotiating New Government Contracts Amidst the Global Pandemic

Government Contracts Legislative and Regulatory Update – March

Regulation update

The March edition of Dentons’ monthly legislative and regulatory update is available!

, ,

Government Contracts Legislative and Regulatory Update – March

Existing Federal Economic Assistance Options for Small Businesses Affected by the Coronavirus (COVID-19)

While the existing federal economic assistance option with the U.S. Small Business Administration (“SBA”), called Economic Injury Disaster Loans (“EIDLs”), have existed for some time, the Coronavirus Preparedness and Response Supplemental Appropriations Act, 2020 (P.L. 116-123) increases the amount made available to the SBA to use for EIDLs to $197.2 million.

EIDLs are low-interest federal disaster loans of up to $2 million offered by the SBA to small businesses, as well as private, non-profit organizations in all U.S. states and territories to help alleviate economic injury directly caused by COVID-19. EIDLs may be used to pay fixed debts, payroll, accounts payable, and other bills that cannot be paid due to the impact of COVD-19. See 13 C.F.R. § 123.303(a).

Importantly, loan proceeds may not be used to:
• Refinance existing debt;
• Repay other SBA loans or loans from another federal agency;
• Pay, directly or indirectly, any taxes, fines or penalties;
• Repair physical damage; or
• Pay dividends or other disbursements to owners, partners, officers or stockholders, except for reasonable remuneration directly related to their performance of services for the business.

13 C.F.R. § 123.303(b).

Small businesses that need working capital to help meet their financial obligations should consider applying for an EIDL. For more information on EIDLs, what constitutes an eligible “small business,” and how to apply for EIDLs, please see the full client alert here.

, ,

Existing Federal Economic Assistance Options for Small Businesses Affected by the Coronavirus (COVID-19)

US DoD Issues Class Deviation Regarding an Increase in Progress Payment Rates in Response to the Coronavirus National Emergency

March 22, 2020

On March 20, 2020, the Department of Defense (“DoD”) issued Class Deviation 2020-O0010 (the “Deviation”) providing that, effective immediately, in response to the coronavirus national emergency, the progress payment rates at Defense Federal Acquisition Regulation Supplement (“DFARS”) § 232.501‑1 are increased to 90% for large business concerns and 95% for small business concerns.  Pursuant to the Deviation, DoD contracting officers (“COs”) are required to use the following clauses attached to the Deviation:

  • DFARS § 252.232-7004, DoD Progress Payment Rates (DEVIATION 2020-O0010), in lieu of the clause at DFARS § 252.232-7004;
  • Federal Acquisition Regulation (“FAR”) § 52.232-16, Progress Payments (DEVIATION 2020‑O0010), in lieu of the clause at FAR § 52.232-16; and
  • Alternate II (DEVIATION 2020-O0010), in lieu of Alternate II of FAR § 52.232-16.

The Deviation affects all DoD contracts, that is, it applies to existing and future DoD contracts. 

The Deviation constitutes a modification to the terms of affected contracts that already exist.  Because the DoD CO assigned to the existing contract is the only individual with the actual authority to execute and memorialize the change in progress payment rates pursuant to the Deviation, the Deviation is effective only upon the DoD CO issuing a contract modification. See FAR § 43.102(a) (providing that only COs with authority are empowered to execute contract modifications on behalf of the government); see also Winter v. Cath-dr/Balti Joint Venture, 497 F.3d 1339, 1344 (Fed. Cir. 2007) (stating that an agent of the government must have actual authority to bind the government to modify contracts; apparent authority is not sufficient).  Accordingly, contractors are advised to request a block change modification from their assigned DoD CO to implement the Deviation on all existing DoD contracts.

US DoD Issues Class Deviation Regarding an Increase in Progress Payment Rates in Response to the Coronavirus National Emergency

Supply Chain Impact of President Trump’s Executive Order Under the Defense Production Act

March 21, 2020

On March 18, 2020, in response to bipartisan calls from Congress and governors across the US, President Trump issued an executive order finding that health and medical resources needed to respond to the spread of COVID-19 meet the criteria under the Defense Production Act (DPA) to be given priority for purposes of supporting the national defense. The order identifies personal protective equipment (PPE) and ventilators as specific types of health and medical resources that will now be given priority. Examples of PPE the order is likely to cover include masks, goggles, gowns and gloves. Other health and medical resources, such as diagnostic test supplies, may soon be added to the list as the executive order delegates authority to the Secretary of Health and Human Services (HHS) to identify additional specific health and medical resources that meet applicable criteria under the DPA.

Because ongoing US production of essential health and medical resources is already addressing shortfalls related to the domestic impact of the COVID-19 pandemic, some experts, including at the Center for Strategic and International Studies, believe that the President’s invocation of the DPA may be used principally to provide financial incentives for increased and expanded production efforts. Moreover, soon after issuing the order, President Trump shared via social media that he, “only signed the [the order] … should we need to invoke it in a worst case scenario in the future.” In response, expressing the collective sense of urgency of state governments throughout the US, in a March 19, 2020, memorandum to the President and Vice President Mike Pence, the National Governors Association included in its list of top state priorities in response to the COVID-19 outbreak, “guidance on implementation of [the] Defense Production Act to include what health and medical resources Secretary of Health and Human Services Azar is prioritizing under his new authority.”

This advisory provides an overview of the DPA and what this executive order could mean for government contractors and their supply chains.

As discussed in our prior advisory, the DPA provides the President and delegated federal agencies the authority to essentially force private companies to prioritize orders rated for national defense. Rated orders may cover not only the manufacture and delivery of goods, but may also apply to services. What this means, in practice, is that companies must put the federal government’s orders at the front of the line to ensure timely delivery under a rated order. Companies receiving a rated order must also place rated orders with their suppliers (with limited exceptions) to meet delivery requirements, which means that entire supply chains may soon be subject to rated order requirements.

Many DoD contractors and subcontractors are already very familiar with the Defense Priorities and Allocation System (DPAS), as implemented by regulations issued by the Department of Commerce. 15 C.F.R. 700 et seq. Companies may be less familiar with the Health Resources Priorities and Allocations System, as implemented by the Department of Health and Human Services. 45 C.F.R. 101 et seq. The President’s recent executive order very likely will mean that private companies that have either never done business with the federal government or have done so on more routine “commercial item” basis may suddenly be faced with rated orders. Rated orders must be accepted or rejected in writing within specified periods of time. Moreover, the bases for rejection are specific and narrow. Ultimately, willful refusal to comply with a rated order can subject private companies and individuals to a variety risks, including potential criminal charges.

Companies with products and services that may fall within the scope of health and medical resources should immediately familiarize themselves with the DPA, its implementing regulations, and any nationwide priorities and regulations that may be established by the HHS Secretary. Given the pace of the pandemic and the changes and disruptions to the supply chain that are already being observed, another key consideration is how the DPA and the national security needs that it seeks to address in operation collide with state and local police power. Specifically, contractors and/or their suppliers are very likely located in places where workers have been encouraged or directed to work from home, among other social distancing practices that have been recommended or mandated. Similarly, business operations have likely been impacted by travel restrictions, significantly limited airline schedules, and regulations in foreign jurisdictions limiting the export of materials required to produce the health and medical resources necessary to combat COVID-19 that are in short supply in the US. In the most extreme cases, some local or state jurisdictions have issued orders for their residents to “shelter in place.”

California issued such an order, effective Thursday, March 19. In the face of these challenges, accepting and performing a rated order (or any other order) may well prove impossible. State and local officials and the federal government are working to provide clarity that the DPA allows continued performance by contractors and their employees not withstanding local orders limiting or closing businesses. While this is developing by the hour, the Department of Homeland Security issued guidance confirming that contractors performing defense or health related contracts are part of the nation’s “critical infrastructure.”

From a supply chain perspective, companies receiving rated orders must recognize that orders they place to support performance of a rated order must also be issued as a rated order, unless exceptions apply. Issuing a rated order properly requires:

  • Specifying the appropriate rating on the order, including special language in the order so that the supplier is notified of its obligations;
  • Obtaining timely written acceptance or rejection;
  • Identifying a specific delivery date for items being ordered; and
  • Obtaining timely acceptance or rejection of any changes made to the order, which amounts to a new rated order.

Any company combining rated items and un-rated items in the same order must separately designate those times. Further, a company does not need to issue an order as rated if it is under certain dollar thresholds, unless the company cannot ensure timely delivery without using the rating.

The issuance of rated orders for certain medical technologies may also have a wider impact in the overall supply chain that affects other contractors. This may include electronic components that are common to a variety of products, including medical devices. In addition, we have seen examples, such as in the UK, where the general manufacturing industry is being drafted to transition to medical device manufacturing. The UK Government, for example, asked both Rolls-Royce and Ford to transition to manufacturing ventilators. Similar realignment of the industrial base both in the US and abroad could have far reaching consequences for the overall supply chain for a variety of goods and services.

If entities receiving rated orders encounter problems, there are procedures to follow to secure what is known as special priorities assistance. There are also avenues to appeal the rating applied to orders and the rating itself.

Ultimately, the discussion above highlights the complexity and risk associated with the DPA and DPAS that private companies with no prior background in the area will soon be facing. The best way to deal with these extraordinary circumstances effectively is to be proactive and to secure assistance from knowledgeable counsel, where and when appropriate.

Stay up-to-date with all of our insights and guidance by visiting our US COVID-19 hub here.

Supply Chain Impact of President Trump’s Executive Order Under the Defense Production Act

Voluntary vs. Involuntary Stop Work: What contractors should consider as the COVID-19 pandemic evolves

March 17, 2020

The COVID-19 public health emergency that has been unfolding over the past weeks and months is predicted to get far worse before it gets better. On Friday March 13, 2020, the President declared a national emergency to combat the virus and we have seen unprecedented cancellations relating to international travel, sporting events and large public gatherings. There also have been employer-issued mandates that employees work from home. As part of our on-going series, this advisory addresses some of the issues government contractors should carefully consider in connection with interruptions to their contract work.

Indeed, as the pandemic evolves, there is increased potential that government contractor operations will be impacted in a variety of ways, some of which may be more likely than others. Under these circumstances, contractors should be proactively identifying and considering likely impacts and how best to position themselves to mitigate those impacts. For example, contractors may encounter circumstances where they conclude they must temporarily cease operations or direct their non-essential personnel to work remotely. Or they may be having difficulty securing material or other resources due to impacts in the supply chain. While all of these impacts on work trace back to COVID-19, there are likely intervening causes that, depending on relevant contract terms, may provide avenues for the contractor to excuse nonperformance and avoid default or, alternatively, seek recovery from the government for impacts associated with stopped or delayed work.

First, it will be important to distinguish between a contractor’s voluntary work stoppages and involuntary work stoppages.  Our prior advisory noted that if a contractor is temporarily unable to continue contract performance, i.e., is involuntarily delayed or impacted due to the pandemic, it is likely that force majeure principles would operate to excuse non-performance and prevent a government default termination. On the other hand, if it is proven that the contractor voluntarily or unreasonably stopped work or failed to perform, the contractor may risk default termination. Depending on the circumstances, there may also be an order or direction from the government to change or stop work, which may provide an avenue for the contractor to secure an equitable adjustment to compensate for delays and cost impacts. Accordingly, it will be critical to understand, anticipate and distinguish between situations where a delay or disruption could create a risk of default, and situations where a delay or disruption is justified and excusable, or is the government’s responsibility.

Second, contractors should be thinking ahead about what they could or would do if they experience difficulties performing their government contracts as a result of COVID-19. The magnitude of the impacts and delays contractors may experience, of course, will depend upon the nature of their work and their particular circumstances. Similar to what occurs during a shutdown period, any work that is dependent upon government action may be delayed, including the issuance of new work or task orders, technical direction, first-article acceptance, approvals to test, acceptance inspections, and payments. In addition, in instances where contractors are performing at government facilities, contractors’ employees may have limited or no access to these facilities.

To the extent that a contractor suffers any adverse impacts due to COVID-19, it may be able to recover costs associated with these impacts pursuant to its contract terms. See, e.g., FAR 52.242-14, Suspension of Work; FAR 52.242-15, Stop-Work Order; FAR 52.242-17, Government Delay of Work; FAR 52.243-1, Changes – Fixed-Price. Importantly, unlike government shutdown circumstances, establishing that performance interruptions were caused by the government, through a contractual order, will be important. It is possible, however, that government contracting officers will avoid issuing a written order for the contractor to stop work. In this regard, issues of authority will be important to consider. In the event that the federal government issues an order that impacts contract performance, contractors should make every effort to obtain direction in writing from their contracting officer. 

In instances where contractors are performing cost reimbursable contracts, even if the Stop Work clause is not incorporated into the contracts, any additional costs attributable to disruption in work due to COVID-19 likely are recoverable as allowable costs of performance. If the disruption significantly increases costs or the level of effort required, contractors may seek an adjustment to the contract’s estimated costs and/or fee pursuant to the Changes clause, FAR 52.243-2.

Where no stop-work order is issued and contractors continue performing their fixed-price contracts, but have been hindered by COVID-19, recovery of any increased costs is less certain because the government likely would assert that the COVID-19 public health emergency is entirely outside of its control. Additionally, where the President or federal health officials issue orders that adversely affect contract performance, the government likely will take the position that such action constitutes a sovereign act that precludes recovery.

Determining who is responsible for the costs and delays resulting from COVID-19 ultimately depends on the facts and circumstances, as well as relevant contract provisions. Nevertheless, similar to those best practices applicable in a government shutdown, contractors can best position themselves for recovery by adhering to the following guidance:

  • Document any cost impacts and performance delays that result from government contractual action. There is risk that a government direction resulting from, or in reaction to, other government orders regarding COVID-19 could be viewed as a sovereign act, precluding any contractual recovery. To mitigate this risk, ensure that you have received, or will receive, a stop-work notice or some other contractual direction and that this direction is maintained in the contract file. If no written guidance is issued, consider asking the contracting officer to do so as appropriate.
  • Costs resulting from COVID-19 disruptions may be recoverable depending on the contract type. When contractual direction exists, costs reasonably incurred as a result of the government order may be recovered through the stop-work order, or the contract’s suspension of work, government delay of work, or changes clauses, so long as the impacts and delays arise during a period where the contract is funded.
  • Schedule impacts from a government-ordered stop-work order should be addressed through extensions to the period of performance. Schedule impacts resulting from a government order also likely are addressable through the stop-work order, suspension of work, government delay of work, or changes clauses.
  • Contractors should mitigate the impact to contracts. While contractors may be entitled to recover costs and/or receive schedule adjustments to address the impact of a government- ordered stop-work, contractors are responsible for taking reasonable actions to reduce the cost and/or schedule impact. These actions may include examining the feasibility of workarounds, diverting employees to commercial efforts (if possible), and potentially furloughing employees. If a contractor fails to take mitigation steps, the government may assert that the contractor acted unreasonably and may attempt to reduce the total costs and/or length of the extension provided to address the impact of the stop-work.
  • Cost and schedule impacts should be carefully tracked. To recover increased costs or receive a schedule adjustment, contractors must be able to demonstrate that the cost or schedule impact occurred and tie the impact to the government’s contractual order or fault. Employees that are prevented from performing work, therefore, should provide detailed time entries and record their labor costs in segregated accounts to demonstrate the labor cost impact of the disrupted period. Other cost impacts, such as costs associated with rescheduling work or redirecting employees to perform commercial work (if possible), should be similarly documented. Likewise, any schedule impact should be fully documented and demonstrated through a critical path or similar schedule analysis.
  • Take appropriate actions with respect to subcontractors. If a stop-work order is issued by the government, then contractors should immediately issue similar stop-work orders to any affected subcontractors. If no stop-work order is issued by the government, managing subcontractors becomes more complicated.
  • Contractors performing work as subcontractors on government prime contracts should seek clarity and instructions from their prime contractor customers regarding any potential impacts COVID-19 may have on performance. To the extent that any subcontracts are stopped or suspended , consistent with the guidance above, subcontractors should ensure that they mitigate any resulting costs or schedule impacts, identify and accumulate any resulting costs, and seek contract direction from their prime contractor customers as appropriate.
  • To the extent possible, communicate with the contracting officer. Consider requesting guidance on whether a contracting activity is an essential activity or service that must continue, regardless of any orders regarding COVID-19.

The rippling impacts and effects of this unprecedented modern public health emergency likely will be with us for some significant amount of time. As always, contractors must be proactive in order to best position themselves to maximize any cost recoveries and/or contract extensions necessary to address the impact of COVID-19, including documenting, on a contract-by-contract basis, why certain actions taken were reasonable.

Stay up-to-date with all of our insights and guidance by visiting our US COVID-19 hub here

Voluntary vs. Involuntary Stop Work: What contractors should consider as the COVID-19 pandemic evolves

Federal Contracting Implications of President Trump’s National Emergency Declaration In Response to the Coronavirus (COVID-19) Pandemic

March 16, 2020

Dentons has formed a COVID-19 Client Special Situations Team and Client Resources Hub that stands ready to assist contractors in addressing the full range of issues, both in the US and globally, that may arise in connection with the COVID-19 outbreak. This advisory is the latest update in a series of alerts that address various aspects in which the contracting community may be affected. This advisory focuses on the implications of President Trump’s emergency declaration under the Stafford Act and the government’s use of the Defense Production Act and similar authorities to acquire goods and services that may be necessary to combat COVID-19.

On Friday, March 13, 2020, President Trump declared a national emergency relating to the coronavirus (COVID-19) pandemic. This emergency declaration makes available billions of dollars in federal disaster relief funds to state and local governments pursuant to the Robert T. Stafford Disaster Relief and Emergency Assistance Act (Stafford Act), 42 U.S.C. ch. 68. Federal Emergency Management Agency (FEMA) administers the funds, pursuant to specific federal regulations, and generally makes them available to state and local governments in the form of grants. The state and local governments will further administer the funds for specific programs through subgrants and procurement contracts to support the COVID-19 response and relief effort.

In addition to the funds made available under the Stafford Act, contractors also should be cognizant of the fact that the federal government might exercise its authority under the Defense Production Act of 1950, 50 U.S.C. §§ 4501 et seq., which is implemented by the Defense Priorities and Allocations System (DPAS), 15 C.F.R. § Pt. 700, to rapidly respond to the COVID-19 pandemic. Under DPAS, the government has the authority to prioritize government contracts for goods and services over competing customers, to allocate or control the general distribution of materials, and to offer incentives within the domestic market to enhance the production and supply of critical materials and technologies when necessary to respond to a national emergency. Contractors that have prime contracts, subcontracts or purchase orders subject to DPAS generally must quickly accept DPAS-rated orders within a short timeframe (10 to 15 days), and may only reject a rated-order in very limited circumstances. Additionally, prime contractors and subcontractors are required to flowdown these rating requirements to suppliers, as necessary to meet delivery requirements.  It is therefore important for contractors to be aware of which of their prime contracts, subcontracts and purchase orders are rated.

While it is unlikely that the government would exercise the more extreme authority granted under DPAS and effectively commandeer manufacturing and other types of facilities in order to produce critical medical supplies or to support other emergency relief efforts, contractors should further be mindful that the government could also authorize companies to use certain goods and technology that is patented by other companies without the consent of the patent holder. Specifically, pursuant to the Bayh-Dole Act, 35 U.S.C. ch. 18, or 28 U.S.C. § 1498, the federal government may authorize a company to produce, for example, critical pharmaceutical products, testing equipment or other essential items that are patented by another company to combat CoVID-19. Together, these authorities essentially authorize the US government to license and authorize the practice of patented inventions by industry competitors without regard to whether the patented technology was developed with government funding or exclusively at private expense. While patent holders are not without recourse, a patent holder’s recourse is typically limited to relief from the federal government in the form of royalty payments or damages—not from the companies who have received appropriate authorization and consent to use the patented items. Notably, however, in cases involving subject inventions funded by it, the government, pursuant to the Bayh-Dole Act, may exercise its “march-in” rights that permit the government to require the patent holder to license the invention to third parties. If the patent holder fails to do so, the Bayh-Dole Act permits the government to directly license the patented technology to non-patent holders upon terms that are reasonable under the circumstances. This may presumably include the payment of reasonable royalties to the patent holder, but the relevant provision of the Bayh-Dole Act (35 U.S.C. § 203) does not specifically require the payment of such royalties, creating risk that the patent holder may not receive the compensation that might normally be due. While the Bayh-Dole Act and its implementing regulations in the Federal Acquisition Regulation (FAR) apply to small businesses and non-profit organizations, the Act authorizes the government to extend the Act’s requirements to all contractors. See 35 U.S.C. § 210(c); FAR Subpart 27.3. In this regard, the Department of Defense has extended these requirements, among others, to large contractors through a specific clause, Defense Federal Acquisition Regulation Supplement (DFARS) 252.227-7038, which includes the government’s march-in rights. See DFARS 252.227-7038(h). Therefore, contractors of all sizes should be aware of the government’s ability to exercise these rights.

The national emergency surrounding COVID-19 creates a situation in which the government may utilize its vast national security powers and emergency resources to combat the virus. Contractors must be aware of the unique issues that may arise under these circumstances as the consequences of noncompliance may be drastic.

Please contact any of the authors if you require additional guidance on specific issues.

Federal Contracting Implications of President Trump’s National Emergency Declaration In Response to the Coronavirus (COVID-19) Pandemic